1. General
All purchasing agreements are accepted and executed on the understanding that the purchaser is bound by these General Sales and Supply of Goods Agreement. Any deviations
from these are only valid when these are confirmed by us in writing.
2. Quotations
When nothing else is agreed in writing, a quotation is valid for 30 days from date of issuing. The prices are quoted ex works (according to Incoterms 2000), excl. taxes.
3. Orders
Orders for goods which are fabricated according to customers’ specifications or which have been specially purchased to customers cannot under normal circumstances be
cancelled.
Orders for goods from our standard range of goods can only be cancelled with our prior written agreement. A Restocking charge will apply.
The prices stated in our order confirmation are ex works (according to Incoterms 2000) excl. packing and taxes unless otherwise clearly stated in writing on the order confirmation
itself.
4. Delivery Times
When quoting or confirming an order, the delivery times or dates are stated to the best of our judgement. They are approximate only and, unless otherwise expressly stated, time
is not of the essence for delivery of the Products.
Aeropacific reserves the right to delay or amend the delivery date in the following cases:
a) When purchaser changes specifications
b) When deliveries of goods or labour which the purchaser provides himself or has assigned third party to supply, are delayed.
c) In case of force majeure, according to paragraph 14.
In above mentioned items a) and b) we further reserve the right to adjust the confirmed price according to the costs which may have been incurred due to the above
circumstances.
5. Drawings, Descriptions and Documentation
The ownership of all drawings, descriptions, documentation and suggestions included in any quotation, order confirmation or delivery is at all times held by Aeropacific. Neither
may these be copied, reproduced, passed to third party nor in any other way brought to the knowledge of a third party without the prior written consent of Aeropacific.
6. Payment
Unless otherwise stated in writing, the terms of payment are net cash on delivery. Aeropacific has the right to charge interest from the full amount of the invoice at the rate of 8%
above the Bank of England base rate from time to time as of the date due for payment. If the purchaser is not able to receive the goods on the agreed delivery date, the delivery is
payable when the delivery is reported ready for despatch.
At partial deliveries of the goods, each delivery is payable on delivery and in case payment is not received on the date due, we reserve the right to withhold further deliveries
without losing the right to require the completion of the contract.
The purchaser does not have the right to withhold payment owing to possible counterclaims or claims against Aeropacific, which have not been approved in writing by us.
Aeropacific maintains the ownership of the goods until Aeropacific has received the full payment, including interest, of all the goods supplied in accordance with our order
confirmation.
7. Packing
Packing requested by the purchaser or found necessary for the safe arrival of the goods will be charged to the purchaser. No credit will be allowed for returned packing.
8. Shipment
Any agreed trade term shall be construed in accordance with the INCOTERMS in force at the formation of the contract.
If no trade term is specifically agreed, the delivery shall be ex works. If, in the case of delivery ex works, Aeropacific, at the request of the purchaser, undertakes to send the goods
to their destination, the risk will pass not later than when the goods are handed over to the first carrier. Partial shipments shall be permitted unless otherwise agreed.
9. Claimant’s Default
If, after the acknowledged date of delivery, the purchaser fails to take delivery of the goods, Aeropacific is entitled to arrange storage and insurance of the goods on behalf of the
purchaser and all charges for storage, insurance and demurrage shall be payable by the purchaser.
Should the purchaser fail to collect the goods despite written notice from Aeropacific, we reserve the right to sell the goods – also goods manufactured specially according to
purchaser’s specifications – at the best price on behalf of the purchaser and charge all costs connected herewith to the purchaser.
10. Return of Goods
Under no circumstances may goods supplied against a firm order be returned without the purchaser having first applied for and obtained the written consent of Aeropacific. A
handling / re-stocking charge may be deducted from any credit allowed.
11. Claims
Any claim on delivered goods shall be submitted in writing not later than 7 days after receipt of the goods.
12. Warranty
For all units or parts fabricated by Aeropacific, we provide the following warranty for 12 calendar months after the date of delivery:
If a fault is detected in the construction, material or workmanship of any part fabricated and designed by Aeropacific the material shall be returned free of charge (return to base)
to Aeropacific
As soon as possible after receipt, Aeropacific will within normal working hours repair or renew the parts as required. If the repair takes place on site, we reserve the right to debit
the customer for travel costs and accommodation. The warranty given in this clause is subject to the provisos that the purchaser has followed the instructions issued by
Aeropacific in relation to the goods and that it has been applied according to the way of function agreed in writing.
Our responsibilities and warranty cover only faults and defects occurred during correct use.
Our warranty does not cover faults and defects occurred due to lack of maintenance, incorrect mounting or use carried out by the purchaser or third party, alterations made
without our written consent, faults in any sort of repair carried out by the purchaser or third party or normal wear or tear. In case the purchaser has asserted claim on
Aeropacific according to the afore-mentioned statement and there proves to be no fault or defects for which Aeropacific can be held responsible, Aeropacific reserves the right
to debit the purchaser with any costs and man-hours that the claim has caused Aeropacific.
Replacement or repaired parts will be forwarded for Aeropacific’s account.
Replaced parts shall be put at our disposal and remain our property. The afore-mentioned statement is not valid for external, sub-supplied parts, for example plugs and cables,
contained in our delivery. For such parts only the warranty issued by the sub supplier is recognised.
Aeropacific reserves the right to suspend and/or refuse warranty service where the goods or related charges are not fully paid.
13. Product Liability
Aeropacific shall be liable for personal injury only if it is proved, that such injury was caused by fault or negligence on the part of Aeropacific or others for whom Aeropacific is
responsible. Indemnity for personal injury can never exceed the level of damages prevailing at the time in question in NZ law.
Aeropacific is on similar conditions as for personal injury, liable for damage to real property and personal property, however the amount of indemnity can never exceed 5 million
pound sterling incl. interest and costs.
To the extent that Aeropacific might incur product liability towards any third party, the purchaser shall indemnify Aeropacific as far as Aeropacific’s liability has been limited by
the present sales and delivery conditions.
Any claim lodged by a third party against Aeropacific or the purchaser must be notified to the other party without delay.
Aeropacific and the purchaser shall be mutually obliged to let themselves be summoned to the court for examination of claims for damages lodged against either of them on the
grounds of damage allegedly caused by the goods supplied.
Irrespective of the afore-mentioned statement and irrespective that it has been proved, that Aeropacific has acted negligently, Aeropacific accepts no liability for production
losses, loss of profit, other indirect losses or consequential loss of any kind, no matter if the claim is supported by common liability rules or any other conditions.
14. Force Majeure
Aeropacific shall be under no liability for any loss or injury suffered by the purchaser and for late or lack of supply when this is caused by force majeure such as (but not limited
to) war, fire, drought, failure of plant or power supply, lock-out, strike or other actions taken by employees, civil troubles, legislation or public interference, import and/or export
prohibitions, the lack of or incomplete delivery from sub supplier, insufficient labour force, or any other cause beyond our control which may delay or interfere with the
fabrication and delivery of the sold goods. If complete or punctual delivery is temporarily obstructed by one or more of the afore-mentioned circumstances, the delivery is
suspended for a period equal to the duration of the obstruction with the addition of a period reasonable for the normalisation of the situation. Delivery on the date thus
postponed is in any respect considered in time.
In the event of force majeure we may choose between terminating the contract or part hereof or alternatively deliver the goods agreed on according to the before mentioned
conditions and delays.
15. Governing Law and Jurisdiction
This agreement shall be governed by and construed in all respects in accordance with NZ law. The international rules for the interpretation of trade terms (INCOTERMS) shall
apply but where they conflict with this agreement, this agreement shall prevail.
Nothing in this clause shall limit the right of Aeropacific to take proceedings against the Purchaser in any other court of competent jurisdiction, nor shall the taking of proceedings
in any one or more jurisdiction preclude Aeropacific from taking proceedings in any other jurisdiction, whether concurrently or not, to the extent permitted by the law of such
other jurisdiction.
All purchasing agreements are accepted and executed on the understanding that the purchaser is bound by these General Sales and Supply of Goods Agreement. Any deviations
from these are only valid when these are confirmed by us in writing.
2. Quotations
When nothing else is agreed in writing, a quotation is valid for 30 days from date of issuing. The prices are quoted ex works (according to Incoterms 2000), excl. taxes.
3. Orders
Orders for goods which are fabricated according to customers’ specifications or which have been specially purchased to customers cannot under normal circumstances be
cancelled.
Orders for goods from our standard range of goods can only be cancelled with our prior written agreement. A Restocking charge will apply.
The prices stated in our order confirmation are ex works (according to Incoterms 2000) excl. packing and taxes unless otherwise clearly stated in writing on the order confirmation
itself.
4. Delivery Times
When quoting or confirming an order, the delivery times or dates are stated to the best of our judgement. They are approximate only and, unless otherwise expressly stated, time
is not of the essence for delivery of the Products.
Aeropacific reserves the right to delay or amend the delivery date in the following cases:
a) When purchaser changes specifications
b) When deliveries of goods or labour which the purchaser provides himself or has assigned third party to supply, are delayed.
c) In case of force majeure, according to paragraph 14.
In above mentioned items a) and b) we further reserve the right to adjust the confirmed price according to the costs which may have been incurred due to the above
circumstances.
5. Drawings, Descriptions and Documentation
The ownership of all drawings, descriptions, documentation and suggestions included in any quotation, order confirmation or delivery is at all times held by Aeropacific. Neither
may these be copied, reproduced, passed to third party nor in any other way brought to the knowledge of a third party without the prior written consent of Aeropacific.
6. Payment
Unless otherwise stated in writing, the terms of payment are net cash on delivery. Aeropacific has the right to charge interest from the full amount of the invoice at the rate of 8%
above the Bank of England base rate from time to time as of the date due for payment. If the purchaser is not able to receive the goods on the agreed delivery date, the delivery is
payable when the delivery is reported ready for despatch.
At partial deliveries of the goods, each delivery is payable on delivery and in case payment is not received on the date due, we reserve the right to withhold further deliveries
without losing the right to require the completion of the contract.
The purchaser does not have the right to withhold payment owing to possible counterclaims or claims against Aeropacific, which have not been approved in writing by us.
Aeropacific maintains the ownership of the goods until Aeropacific has received the full payment, including interest, of all the goods supplied in accordance with our order
confirmation.
7. Packing
Packing requested by the purchaser or found necessary for the safe arrival of the goods will be charged to the purchaser. No credit will be allowed for returned packing.
8. Shipment
Any agreed trade term shall be construed in accordance with the INCOTERMS in force at the formation of the contract.
If no trade term is specifically agreed, the delivery shall be ex works. If, in the case of delivery ex works, Aeropacific, at the request of the purchaser, undertakes to send the goods
to their destination, the risk will pass not later than when the goods are handed over to the first carrier. Partial shipments shall be permitted unless otherwise agreed.
9. Claimant’s Default
If, after the acknowledged date of delivery, the purchaser fails to take delivery of the goods, Aeropacific is entitled to arrange storage and insurance of the goods on behalf of the
purchaser and all charges for storage, insurance and demurrage shall be payable by the purchaser.
Should the purchaser fail to collect the goods despite written notice from Aeropacific, we reserve the right to sell the goods – also goods manufactured specially according to
purchaser’s specifications – at the best price on behalf of the purchaser and charge all costs connected herewith to the purchaser.
10. Return of Goods
Under no circumstances may goods supplied against a firm order be returned without the purchaser having first applied for and obtained the written consent of Aeropacific. A
handling / re-stocking charge may be deducted from any credit allowed.
11. Claims
Any claim on delivered goods shall be submitted in writing not later than 7 days after receipt of the goods.
12. Warranty
For all units or parts fabricated by Aeropacific, we provide the following warranty for 12 calendar months after the date of delivery:
If a fault is detected in the construction, material or workmanship of any part fabricated and designed by Aeropacific the material shall be returned free of charge (return to base)
to Aeropacific
As soon as possible after receipt, Aeropacific will within normal working hours repair or renew the parts as required. If the repair takes place on site, we reserve the right to debit
the customer for travel costs and accommodation. The warranty given in this clause is subject to the provisos that the purchaser has followed the instructions issued by
Aeropacific in relation to the goods and that it has been applied according to the way of function agreed in writing.
Our responsibilities and warranty cover only faults and defects occurred during correct use.
Our warranty does not cover faults and defects occurred due to lack of maintenance, incorrect mounting or use carried out by the purchaser or third party, alterations made
without our written consent, faults in any sort of repair carried out by the purchaser or third party or normal wear or tear. In case the purchaser has asserted claim on
Aeropacific according to the afore-mentioned statement and there proves to be no fault or defects for which Aeropacific can be held responsible, Aeropacific reserves the right
to debit the purchaser with any costs and man-hours that the claim has caused Aeropacific.
Replacement or repaired parts will be forwarded for Aeropacific’s account.
Replaced parts shall be put at our disposal and remain our property. The afore-mentioned statement is not valid for external, sub-supplied parts, for example plugs and cables,
contained in our delivery. For such parts only the warranty issued by the sub supplier is recognised.
Aeropacific reserves the right to suspend and/or refuse warranty service where the goods or related charges are not fully paid.
13. Product Liability
Aeropacific shall be liable for personal injury only if it is proved, that such injury was caused by fault or negligence on the part of Aeropacific or others for whom Aeropacific is
responsible. Indemnity for personal injury can never exceed the level of damages prevailing at the time in question in NZ law.
Aeropacific is on similar conditions as for personal injury, liable for damage to real property and personal property, however the amount of indemnity can never exceed 5 million
pound sterling incl. interest and costs.
To the extent that Aeropacific might incur product liability towards any third party, the purchaser shall indemnify Aeropacific as far as Aeropacific’s liability has been limited by
the present sales and delivery conditions.
Any claim lodged by a third party against Aeropacific or the purchaser must be notified to the other party without delay.
Aeropacific and the purchaser shall be mutually obliged to let themselves be summoned to the court for examination of claims for damages lodged against either of them on the
grounds of damage allegedly caused by the goods supplied.
Irrespective of the afore-mentioned statement and irrespective that it has been proved, that Aeropacific has acted negligently, Aeropacific accepts no liability for production
losses, loss of profit, other indirect losses or consequential loss of any kind, no matter if the claim is supported by common liability rules or any other conditions.
14. Force Majeure
Aeropacific shall be under no liability for any loss or injury suffered by the purchaser and for late or lack of supply when this is caused by force majeure such as (but not limited
to) war, fire, drought, failure of plant or power supply, lock-out, strike or other actions taken by employees, civil troubles, legislation or public interference, import and/or export
prohibitions, the lack of or incomplete delivery from sub supplier, insufficient labour force, or any other cause beyond our control which may delay or interfere with the
fabrication and delivery of the sold goods. If complete or punctual delivery is temporarily obstructed by one or more of the afore-mentioned circumstances, the delivery is
suspended for a period equal to the duration of the obstruction with the addition of a period reasonable for the normalisation of the situation. Delivery on the date thus
postponed is in any respect considered in time.
In the event of force majeure we may choose between terminating the contract or part hereof or alternatively deliver the goods agreed on according to the before mentioned
conditions and delays.
15. Governing Law and Jurisdiction
This agreement shall be governed by and construed in all respects in accordance with NZ law. The international rules for the interpretation of trade terms (INCOTERMS) shall
apply but where they conflict with this agreement, this agreement shall prevail.
Nothing in this clause shall limit the right of Aeropacific to take proceedings against the Purchaser in any other court of competent jurisdiction, nor shall the taking of proceedings
in any one or more jurisdiction preclude Aeropacific from taking proceedings in any other jurisdiction, whether concurrently or not, to the extent permitted by the law of such
other jurisdiction.